Contact

WHY US?

We treat every home as our own. Your satisfaction drives everything we do - that’s why we offer honest advice, clear timelines, and guaranteed craftsmanship.

Effective Date: OCTOBER 11,2025
Welcome to HBN Contractors. By accessing or using our website, services, or submitting any inquiry, you agree to comply with the following Terms and Conditions. Please read them carefully before engaging our services.

1. Introduction

HBN Contractors (“we,” “our,” “us”) provides professional home improvement services, including but not limited to solar panel installations, roofing, windows & doors, HVAC & insulation, and kitchen & bath remodeling.
By using our services or website, you agree to these terms, which form a legally binding agreement between you and HBN Contractors.

2. Scope of Services

Our services are provided based on written proposals, estimates, or signed agreements.

• We strive to deliver all work in accordance with local building codes and professional standards.

• Service availability and timelines may vary by location and project requirements.

• Any modifications to project scope, materials, or timeline must be approved in writing by both parties.

3. Estimates & Pricing

All pricing provided in quotes or estimates is based on information available at the time.

• Estimates are valid for 30 days from the date of issuance.

• Final pricing may vary if the project scope changes or unforeseen conditions arise.

• HBN Contractors reserves the right to update pricing or cancel quotes if not accepted within the validity period.

4. Payments

Payments are due according to the schedule outlined in your project agreement or invoice.

• A deposit may be required to initiate services.

• The remaining balance is due upon completion unless otherwise agreed.

• Late payments may incur a service charge or result in suspension of work until payment is received.

We accept major payment methods including credit/debit cards, bank transfers, and certified checks.

5. Warranties

We stand behind our workmanship and materials.

• Workmanship warranties vary by project type but generally range from 1 to 10 years.

• Manufacturer warranties on materials or equipment apply where available.

• Warranty coverage does not include damages caused by external events, improper maintenance, or unauthorized modifications.

6. Cancellations & Rescheduling

If you wish to cancel or reschedule a project, please notify us in writing.

• Cancellations made after work has begun may result in partial charges for materials or labor already expended.

• HBN Contractors reserves the right to reschedule projects due to weather, material availability, or safety concerns.

7. Liability Disclaimer

While we take every precaution to ensure safety and quality, HBN Contractors is not liable for:

• Incidental or consequential damages resulting from delays, unforeseen conditions, or third-party actions.

• Damages resulting from homeowner negligence or failure to follow maintenance recommendations.

Our total liability, under any circumstance, shall not exceed the amount paid for the specific project or service.

8. Intellectual Property

All content, images, logos, designs, and materials on our website are the intellectual property of HBN Contractors.

• You may not copy, reproduce, or distribute any content without our written consent.

• All project images or testimonials shared with permission may be used for marketing and portfolio purposes.

9. Privacy & Data Protection

We respect your privacy.

• Any personal information collected through our website or services will be handled in accordance with our [Privacy Policy].

• We do not sell or share customer data with third parties except as required to fulfill contracted services.

10. Third-Party Partnerships & Affiliates

HBN Contractors may partner with other verified service providers or affiliate networks for certain projects or lead generation.

• Any third-party service engagements are governed by their respective terms.

• We ensure all partners meet our quality and compliance standards.

11. Governing Law

These Terms and Conditions are governed by the laws of [Your State/Province].
Any disputes arising from these terms will be resolved through negotiation or arbitration in [Your City/State], unless otherwise required by law.

12. Updates to Terms

HBN Contractors reserves the right to update these Terms and Conditions at any time.
All updates will be posted on our website with the “Effective Date” listed above. Continued use of our services after such updates constitutes acceptance of the revised terms.

Terms & Conditions